Fact-checked by Grok 2 weeks ago

Astaldi

Astaldi S.p.A. is an multinational founded in 1929 and headquartered in , specializing in the design, development, and operation of infrastructure projects in sectors such as transportation, , , , and environmental works. The has been involved in high-profile projects, including bridges, , highways, and power plants across , the , and the , with a focus on public-private partnerships and concessions. In 2018, Astaldi encountered severe financial distress due to high debt levels, project delays, and exposure to volatile markets like and , prompting it to file for a creditor protection procedure known as "concordato in bianco" under . This crisis led to the abandonment or exit from several contracts, including road and bridge projects in and a concession in , amid disputes with subcontractors and clients over payments and performance. Following creditor negotiations and court approvals, Astaldi underwent restructuring in 2020, with Salini Impregilo (now S.p.A.) acquiring a controlling stake through a €225 million capital injection, enabling the to continue operations as part of the Webuild Group while retaining its brand under the Astaris entity. As of 2025, legacy obligations from the pre-restructuring period persist in , such as enforcement actions related to arbitrations.

History

Founding and Early Years (1929–1950s)

Astaldi was established in 1929 by Sante Astaldi as Astaldi Construction and , initially focusing on and public infrastructure projects within . The firm emerged during a period of infrastructural development under the Fascist regime, emphasizing large-scale construction capabilities in roads, railways, and hydraulic works. Sante Astaldi's background positioned the company to undertake technically demanding contracts, with early operations centered on domestic markets to build expertise and reputation. Prior to , Astaldi participated in significant national projects, including contributions to the Rome-Naples railroad, a key civil works initiative that enhanced connectivity across . The company's portfolio during the 1930s reflected Italy's emphasis on autarkic development and colonial expansion, though primary activities remained on the , involving such as bridges and urban infrastructure. Wartime disruptions from 1939 to 1945 constrained growth, limiting operations to essential maintenance and reconstruction efforts amid material shortages and conflict damage to existing networks. In the immediate postwar years through the 1950s, Astaldi adapted to Italy's reconstruction phase under the and national recovery programs, diversifying into hydroelectric facilities, tunnels, and systems. This era marked the company's shift toward more complex feats, supported by government contracts aimed at modernizing and infrastructure. Family involvement persisted, with Astaldi descendants maintaining oversight, fostering continuity amid economic stabilization and early internationalization signals by the decade's end.

Expansion in Italy (1960s–1990s)

During the 1960s and 1970s, Astaldi scaled up its involvement in Italian infrastructure, executing projects of greater dimension and technical complexity, such as segments of the Autostrada del Sole and the hospital—the latter marking 's inaugural major endeavor. These undertakings aligned with 's postwar economic expansion and public investment in transport and healthcare networks, enabling Astaldi to build expertise in large-scale civil works amid rising domestic demand for modernization. The initiated a phase of internal reorganization for Astaldi, focused on streamlining operations and enhancing competitiveness in the market, which culminated in strategic mergers by the early . This period saw continued engagement in domestic projects, including the completion of the in 1990, reinforcing Astaldi's role in urban rail development. In the , Astaldi accelerated its domestic consolidation through key acquisitions, notably Italstrade and Dipenta—prominent firms in and electromechanical systems—propelling it to become Italy's second-largest . These moves expanded Astaldi's technical capabilities in subsystems and positioned it to bid on increasingly integrated contracts, such as the Lampeggiano Dam completed in 1992, amid a maturing market for complex engineering consortia.

International Growth and Diversification (2000s–2010s)

During the early , Astaldi pursued a deliberate diversification strategy to expand beyond , targeting emerging markets in the and to mitigate domestic cyclical risks and leverage its engineering expertise in . By 2002, the company established a foothold in the , focusing on industrial plant construction, with ongoing efforts noted in annual reports as a means to build regional presence. This approach continued through 2005, emphasizing EPC () contracts to consolidate Astaldi's role as an international . In the mid-2000s, Astaldi accelerated entry into high-growth markets, particularly and , where it secured large-scale transport projects contributing to revenue expansion in neighboring regions. Key Turkish initiatives included Phase 1 of the Gebze-Orhangazi-Izmir Motorway, encompassing 53 kilometers of roadway and the Bay Bridge, one of the world's longest suspension spans at the time of . In , growth stemmed from European contracts, while in , Astaldi entered via mining and healthcare projects, such as underground developments at the copper mine—the world's largest open-pit operation—and hospital facilities. Further diversification reached and reduced exposure in , aligning with a shift toward stable, high-value concessions. The 2006–2010 formalized this push, projecting total group revenues surpassing €2 billion by 2010 through targeted foreign acquisitions and operational scaling. By the mid-2010s, diversification yielded significant results, with activities comprising over 80% of operating revenues in 2015, driven by contracts in 20+ countries focused on , , and sectors. This period marked Astaldi's evolution into a global EPC leader, though it increasingly relied on complex foreign concessions amid rising execution risks.

Financial Crisis and Bankruptcy Proceedings (2017–2018)

In 2017, Astaldi encountered mounting liquidity pressures stemming from elevated burdens incurred through aggressive international project pursuits, compounded by macroeconomic challenges such as the deepening , which impaired cash flows from regional operations. The company's for the fiscal year ending December 31, 2017, revealed strains from high average levels supporting production and commercial activities, alongside external factors like delayed public payments and selective defaults in key markets. By November 2017, market concerns intensified over the necessity of a increase to €400 million, signaling early distress amid broader sector vulnerabilities in firms. These issues escalated in 2018, with Astaldi's net financial debt reaching €1.9 billion and gross debt totaling €2.5 billion as of June 30, driven by underperforming concessions, project delays, and failed asset disposals, including a proposed sale of a bridge concession in . By September 30, 2018, total net financial debt had climbed to €2,013.1 million, prompting to downgrade Astaldi to 'C' on October 1 following the creditor protection filing, reflecting imminent risk. On September 28, 2018, Astaldi filed for admission to Italy's concordato preventivo procedure with the Court, a pre-bankruptcy arrangement allowing temporary protection from creditors to negotiate while continuing operations. The filing outlined a preliminary path involving the transfer of business units via leasing to newly formed subsidiaries owned by creditor-appointed managers, aimed at isolating viable assets from distressed ones. The Court admitted the application on , 2018, granting Astaldi until December 16, 2018—later extended—to submit a formal reorganization plan. Concurrently, on October 5, 2018, the ISDA EMEA Determination Committee confirmed a Bankruptcy Credit Event effective September 27, 2018, triggering settlements due to the filing's implications for debt obligations. This period marked Astaldi's shift from operational continuity under strain to structured judicial intervention, averting immediate but highlighting systemic risks in over-leveraged concessions.

Business Model and Operations

Core Competencies in Construction

Astaldi demonstrated core competencies in (EPC) services for large-scale infrastructure projects, particularly within the transportation sector, where it executed over 100 projects across more than 20 countries as of 2017. The company specialized in developing integrated initiatives that encompassed design, construction, and operational phases, leveraging specialized technical expertise to handle complex, high-value contracts. Key strengths included for transport such as roads, motorways, railways, metros, and ports, often executed under public-private partnership () or build-operate-transfer (BOT) models. Astaldi's capabilities extended to hydraulic, electromechanical, and works, enabling it to deliver technologically advanced projects with a focus on Italian-engineered quality and know-how exportation. This full life-cycle management approach, from feasibility studies to long-term operations, positioned the firm among Europe's top contractors for managing risks in multifaceted developments. In project execution, Astaldi emphasized disciplined selection based on its heritage in heavy civil works, including metro systems and bridge , supported by in-house teams and efficiencies that minimized external dependencies. These competencies were evidenced by its ranking as one of the world's top 50 firms and a leader in Italy's segment prior to financial challenges.

Key Markets and Strategic Focus

Astaldi's primary markets centered on infrastructure, which constituted the core of its , encompassing railways, metros, roads, highways, motorways, bridges, and tunnels. The company executed large-scale () contracts in these areas, leveraging its expertise in complex, technology-intensive projects. Complementary sectors included , such as plants, and management projects involving , facilities, and systems, alongside for hospitals, industrial facilities, and urban developments. This diversified portfolio enabled Astaldi to secure contracts valued in billions of euros, with transportation accounting for the majority of its €3 billion annual revenue prior to its 2018 financial difficulties. Geographically, Astaldi held a dominant position in , where it originated and maintained leadership in domestic development, but strategically expanded internationally to mitigate risks and access growth opportunities. By the mid-2010s, the operated in over 20 countries across (notably and for highways and rail), the Americas (including for hydroelectric and transmission projects, for roads, and emerging entries like ), the , Central and , and the . This presence supported over 100 active projects and a workforce exceeding 11,500 employees globally, with international operations contributing significantly to backlog diversification. Strategically, Astaldi emphasized an integrated model, providing end-to-end services from and financing to , , and , which allowed it to capture higher margins on and public-private partnership () contracts. The company's priorities, as outlined in its 2017-2021 plan, focused on geographical diversification, selective bidding on high-complexity projects, and to sustain growth amid competitive pressures. This approach aimed to balance domestic stability with international revenue streams, though it faced challenges from underbidding risks and market volatility in regions like . Post-2018 restructuring under Webuild's acquisition, these focuses shifted toward consolidation within a larger group framework, but Astaldi's pre-crisis strategy underscored a commitment to contributing to host countries' .

Project Execution and Risk Management Practices

Astaldi's project execution practices emphasized a rigorous multi-step selection involving strategic, technical, financial, economic, and reviews, culminating in approval by the Corporate Director to mitigate execution uncertainties. The company focused on (EPC) contracts, which comprised 83% of its backlog as of December 2017, allowing greater control over timelines and costs in complex like bridges, tunnels, and metros. A dedicated Project Management Officer (PMO) coordinated resources across projects, integrating requirements with certified quality, health, safety, and environmental (QHSE) systems compliant with ISO 9001, 14001, and standards. In select ventures, such as the de airport expansion, Astaldi implemented (BIM) for integrated design, , and handover phases. Risk management was structured around an (ERM) framework, fully operational by 2017, which aligned with board-defined to identify, assess, and mitigate threats in areas like financial structure, , partnerships, and market scenarios through interdepartmental teams and periodic audits. The and System aimed to protect investments by monitoring operations and applying consolidated internal models for risk-adjusted and back-analysis of completed projects. Astaldi maintained a "zero tolerance" policy for corporate social responsibility risks, including anti-corruption assessments covering 100% of operations, and conducted over 350 third-party audits in 2017 to enforce . By 2018, amid financial pressures, the company introduced enhanced protocols, prioritizing low-capital-intensity contracts with predictable cash flows and shifting revenue toward low-risk regions, targeting 72% from such areas by 2022. Despite these frameworks, execution and risk controls exhibited gaps in high-stakes projects, as evidenced by the Falls hydroelectric contract in , where leaked 2016 Nalcor documents cited Astaldi's poor planning, inadequate supervision, rework, and extended breaks as causes of delays and cost escalations exceeding $700 million in contingencies. faltered in efforts, contributing to downgrades to 'B' in November 2017 and 'CCC-' in September 2018 by , which highlighted unmet debt reduction targets and reliance on short-term amid asset disposal delays. These issues underscored limitations in translating ERM policies into consistent operational discipline, particularly under aggressive bidding and concession exposures that amplified vulnerabilities.

Major Projects

Italian Infrastructure Developments

Astaldi's involvement in Italian infrastructure centered on feats, particularly lines and highways, leveraging its expertise in tunneling and large-scale earthworks. The company contributed to the pre-World War II Rome-Naples railroad, a foundational European civil works project that expanded connectivity in . , Astaldi extended its portfolio to modern rail and road networks, emphasizing design-build contracts for complex terrains. In , Astaldi played a key role in the Naples-Bari high-speed/high-capacity railway, part of the . In March 2017, a led by Salini Impregilo (60% share) with Astaldi (40% share) secured a €397 million for the 18 km Naples-Cancello , encompassing 13.5 km of tunnels, viaducts, and 11 bridges to enable speeds up to 200 km/h and reduce Naples-Bari travel time by over 100 minutes upon completion targeted for 2027. In March 2019, Astaldi in won a €608 million for an additional 18.7 km stretch, including further tunneling and track works. Astaldi also handled the Bicocca-Catenanuova of the Palermo-Catania high-speed line, doubling tracks over approximately 30 km to support regional freight and passenger upgrades. Astaldi participated in the Italian segment of the , a 64 km rail link under the connecting and , where it managed exploratory and access tunnels as part of multinational consortia advancing the project's €8 billion main works phase initiated in the . On highways, the firm secured contracts for the Marche-Umbria , a 42 km bidirectional route enhancing central 's , and the Jonica State Road Megalot 3, upgrading 35 km of coastal connectivity in southern regions with bridges and safety improvements. In early , amid financial strains, Astaldi still captured €110 million in contracts for civil works, including rail hubs and road expansions, underscoring its entrenched position despite underbidding risks in competitive tenders. These projects highlighted Astaldi's technical prowess in seismic-prone areas but later exposed execution delays tied to debt burdens.

European Ventures (Romania and Turkey)

Astaldi established a significant presence in starting in the 1990s, executing contracts for highways, , and bridges as part of the country's modernization efforts. Over more than 25 years, the company constructed over 100 kilometers of and lines alongside approximately 250 kilometers of highways. In Romania, Astaldi completed key motorway sections, including the Ogra–Câmpia Turzii segments of the Motorway and the Ciurel , which opened to traffic on September 30, 2020. The firm also secured a €356 million on , 2020, to build over 30 kilometers of the – Motorway, Lot 5, emphasizing challenging terrain with tunnels and viaducts. Additionally, Astaldi participated in a with IHI Infrastructure Systems for the , Romania's longest with a 1,974-meter central span over the , part of a 23-kilometer project that advanced to cable erection and road deck construction by 2020 and opened in 2023. Railway rehabilitation efforts included a €386 million for 36 kilometers of upgrades, involving 17 new bridges, modernization of five existing bridges, one tunnel, and seven passages. Turkey represented a cornerstone of Astaldi's international concessions, with operations spanning over 30 years and focusing on high-profile transport infrastructure. The company held stakes in the Yavuz Sultan Selim Bridge (Third Bosphorus Bridge), the world's widest suspension bridge at the time with towers exceeding the Eiffel Tower's height, which was inaugurated on August 26, 2016, as part of the Northern Marmara Highway concession. Astaldi sold its interest in this €5.5 billion concession on March 19, 2020, amid financial pressures. It also co-financed the Gebze–Orhangazi–İzmir motorway, securing a $600 million loan in 2014 and exploring a sale of the $7 billion project in 2019 due to Turkey's economic volatility. Earlier wins included contracts exceeding $1 billion for additional Turkish infrastructure, though these contributed to Astaldi's exposure to currency fluctuations and delayed payments during the 2018 financial crisis. By 2025, Astaldi's Turkish hospital investments, such as a 51% stake in the country's largest healthcare complex, were under negotiation for transfer. These ventures highlighted Astaldi's strategy of pursuing build-operate-transfer models but exposed it to geopolitical and macroeconomic risks in the region.

North American and Other International Projects

Astaldi's expansion into North America began in the early 1990s through its U.S. subsidiary, Astaldi Construction Corporation, which focused on heavy highway, bridge, and public works projects primarily in Florida. By 2018, the company secured a US$108 million contract as part of a consortium to construct a 5.5-mile segment of the Wekiva Parkway, a toll road extension in Orange and Lake Counties, Florida, involving earthwork, drainage, and bridge construction. However, amid financial difficulties, Astaldi voluntarily defaulted on four Florida Department of Transportation highway projects in April 2019, leading to termination of contracts valued at over US$200 million collectively, with the state citing performance delays and subcontractor payment issues. In Canada, Astaldi's most significant involvement was the Muskrat Falls Hydroelectric Project in Labrador, where its subsidiary Astaldi Canada Inc. signed a CAD 1.1 billion engineering, procurement, and construction contract on December 23, 2013, for the 824 MW facility's powerhouse, intake structure, and spillway civil works. Construction faced challenges including a 2016 agreement on completion terms amid cost overruns, a stop-work order issued by Nalcor Energy on October 19, 2018, due to Astaldi's insolvency proceedings, and subsequent arbitration disputes over delays and extras. In May 2022, an arbitration panel ruled in favor of Nalcor, rejecting Astaldi's claims for additional compensation exceeding CAD 100 million. Astaldi was also fined CAD 175,000 in June 2020 for professional misconduct related to unpermitted structural engineering on the project. Beyond North America, Astaldi pursued opportunities in Latin America, securing contracts in Chile, Mexico, and Honduras. In November 2017, it won a share of nearly €400 million in awards, including highway and infrastructure works in Chile and Honduras. By May 2018, additional contracts totaling €193 million were awarded for projects in Chile, such as road expansions, and Mexico, focusing on civil engineering tasks. These efforts represented Astaldi's diversification into emerging markets but were hampered by the company's broader financial strain, resulting in limited completion data and integration into larger consortia post-2018.

Controversies and Criticisms

Underbidding and Performance Failures

Astaldi's participation in the Muskrat Falls hydroelectric project in Newfoundland and Labrador, Canada, exemplified issues arising from aggressive low bidding. In November 2013, Astaldi Canada Inc. secured a major contract valued at approximately CAD 1.1 billion as the lowest bidder among competitors for civil works including the , and powerhouse foundations, despite the bid exceeding Nalcor Energy's internal sanction estimates by CAD 300 million. Critics, including project overseers, attributed the low bid to Astaldi's underestimation of site-specific challenges such as harsh winter conditions, stringent North American labor and safety standards, and logistical complexities in a remote location, which Nalcor accepted to control overall project costs. Performance failures quickly emerged post-award, with Astaldi exhibiting slow , inadequate , and repeated in meeting milestones. A forensic audit later identified $1.2 billion in cost overruns directly linked to Astaldi's shortcomings, including suboptimal work execution rates and misalignment with contractual quality benchmarks, forcing Nalcor to allocate additional resources and incur penalties. Project managers described Astaldi as a "problem " that struggled across multiple fronts, such as insufficient on-site expertise and failure to adapt to local regulatory demands, exacerbating schedule slippages that rippled through the entire Muskrat Falls timeline. Similar patterns of underbidding contributed to disputes in other ventures, such as a Florida Department of Transportation project where Astaldi's materially low bid of $48.96 million undercut competitors, leading to allegations of unfair competition and subsequent performance challenges that prompted administrative review. These incidents reflected broader risks in Astaldi's strategy of prioritizing contract wins through aggressive pricing in competitive tenders, often at the expense of realistic cost forecasting, which strained margins when unforeseen variables like regulatory hurdles or supply chain disruptions materialized. In public-private partnerships, Astaldi's approach aligned with industry critiques of abnormally low bids in infrastructure auctions, where initial underpricing facilitated entry but heightened vulnerability to renegotiation needs and financial distress upon execution shortfalls. Overall, such practices amplified Astaldi's exposure to operational failures, contributing to cumulative losses that undermined its financial stability by 2018.

Debt Accumulation and Mismanagement Allegations

Astaldi's net financial debt stood at approximately €1.26 billion at the end of 2017, reflecting a reduction from €1.39 billion in September of that year due to partial refinancing efforts, but it had already been rising amid aggressive expansion into large-scale concessions and engineering, procurement, and construction (EPC) contracts. By mid-2018, net debt had escalated to €1.9 billion, with gross debt reaching €2.5 billion, driven primarily by unfavorable working capital dynamics, weak free operating cash flow generation from ongoing projects, and delays in critical asset disposals such as the Third Bosphorus Bridge concession in Turkey, where economic turmoil and currency devaluation hindered sales proceeds. These pressures culminated in Astaldi filing for creditor protection under Italy's "concordato preventivo" procedure on September 28, 2018, to restructure up to €2.5 billion in liabilities while avoiding insolvency, amid broader sector challenges including Italian government spending cuts and souring foreign ventures. Rating agencies like Fitch and S&P Global attributed the debt buildup to structural issues, including high leverage from past strategic choices that prioritized growth over liquidity buffers, resulting in significant short-term debt maturities and elevated interest expenses. Allegations of mismanagement emerged from creditors, bondholders, and analysts, who criticized Astaldi's leadership for inadequate oversight of cash flow in high-risk international projects and failure to de-risk the balance sheet through timely divestitures, exacerbating vulnerabilities to external shocks like Turkey's 2018 economic crisis. External auditors, including those reviewing 2018 financials, were unable to issue clean opinions due to insufficient documentation and transparency on going-concern assumptions, fueling claims of opaque financial reporting practices. While Astaldi attributed much of the strain to macroeconomic factors and project delays beyond its control, critics argued that over-reliance on debt-financed expansion without robust contingency planning reflected deeper governance shortcomings, as evidenced by the company's decade-long profitability struggles prior to the crisis.

Muskrat Falls Contract Disputes

Astaldi Canada Inc., a subsidiary of the Italian firm Astaldi S.p.A., served as the primary contractor for the civil works on the Muskrat Falls hydroelectric powerhouse, intake, and spillway as part of the 824 MW Lower Churchill Project in Newfoundland and Labrador, Canada, with the contract awarded in 2013. Disputes arose primarily from project delays attributed to design changes, geological challenges, and scope modifications ordered by the owner, Nalcor Energy's Muskrat Falls Corporation, leading Astaldi to seek contract extensions and additional compensation under the terms of the agreement. Nalcor responded by implementing a non-contractual, good-faith dispute resolution process for time extensions, while providing supplemental financial support amid escalating costs and Astaldi's liquidity strains. Tensions intensified in 2016 when a concrete collapse at the powerhouse site, linked to insufficient supports and flawed formwork, prompted Astaldi to sue a U.S. firm involved, highlighting execution risks but also fueling mutual blame over accountability. By December 2016, Astaldi and Falls Corporation negotiated a completion agreement resolving outstanding commercial items and disputes, subject to approvals, though underlying issues persisted amid the project's broader overruns exceeding initial estimates. Further complications emerged in 2018, including Astaldi's failure to remit $7.8 million in union benefit plan contributions, resulting in liens and lawsuits from workers' representatives, and a stop-work order from Nalcor citing performance shortfalls. Astaldi's parent company's insolvency filing in Italy that year exacerbated cash flow problems, leading to payroll delays and Astaldi's effective termination from the site. The core disputes escalated into formal under the with Astaldi claiming entitlements for variations, and disruptions, while Nalcor withheld approximately $180 million in and pursued counterclaims for alleged non-performance. Independent experts, including SOCOTEC, supported Astaldi's position by analyzing productivity data and rebutting owner counterclaims in reports submitted during proceedings. Project managers testified at the Muskrat Falls Inquiry that Astaldi underperformed, attributing setbacks to the contractor's mismanagement rather than solely owner-directed changes, though the inquiry itself was noted to potentially validate hundreds of millions in additional claims. In June 2020, an Occupational Health and Safety Tribunal found Astaldi guilty of professional misconduct related to the 2016 collapse, imposing the maximum fine and underscoring lapses in site safety protocols. Arbitration concluded in May 2022, with Newfoundland and Labrador Hydro declaring a substantial win, implying rejection of most of Astaldi's monetary claims, though specifics on final awards or offsets remained undisclosed; sources indicated that subcontractors and suppliers with outstanding payments from Astaldi's era had been compensated via project funds. These disputes exemplified Astaldi's broader challenges with fixed-price contracts amid volatile site conditions, contributing to the project's total costs ballooning beyond $13 billion CAD, far exceeding original projections.

Acquisition, Restructuring, and Legacy

Webuild Takeover Process (2019–2021)

In response to Astaldi's deepening financial crisis, marked by over €1.3 billion in debt and ongoing creditor protection proceedings under Italy's concordato preventivo regime initiated in May 2018, Salini Impregilo (later rebranded as Webuild) submitted a preliminary investment offer on February 13, 2019, aiming to acquire a controlling stake while ensuring business continuity for Astaldi's projects. The proposal, part of the broader "Progetto Italia" initiative to consolidate and rescue Italian construction firms, included an initial €225 million capital injection to repay protected creditors and involved selling non-core assets, with Salini Impregilo targeting a 65% ownership post-capital increase. The offer faced initial resistance from some of Astaldi's lenders, including Italian banks wary of further equity dilution and asset transfers, prompting negotiations and updates to the bid by July 16, 2019, which refined terms for asset segregation and creditor repayments totaling around €700 million. Italy's Court of Rome, overseeing Astaldi's restructuring, approved the plan in late 2019 after evaluating competing bids, prioritizing the Salini Impregilo proposal for its feasibility in preserving jobs (over 7,000 affected) and project execution, such as the . The transaction required regulatory nods from bodies like the under EU merger rules, delaying full implementation amid Astaldi's cash flow strains, which necessitated a €86 million bridge loan from earlier in 2019. Execution advanced in 2020, with (post-rebranding in April 2021, though operations continued under the prior name during the deal) finalizing the €325 million capital increase on November 5, 2020, securing 65% control of and integrating key assets like international concessions while ring-fencing riskier exposures into a separate vehicle. This phase involved transferring approximately €4.5 billion in project backlog to , bolstering its order book, though it exposed Webuild to Astaldi's legacy liabilities estimated at €500 million in contingencies. The process culminated in a merger approved by shareholders on April 29-30, 2021, following a March 15, 2021, agreement on an exchange ratio of 0.77 Webuild shares per Astaldi share, alongside a partial spin-off of residual Astaldi assets. Webuild acquired the remaining 33.9% stake from minority holders like Fin.Ast S.r.l. for €170 million by July 31, 2021, achieving full ownership and delisting Astaldi from the Milan Stock Exchange on August 2, 2021. The deal, valued at around €1.7 billion in total commitments including debt assumptions, stabilized Astaldi's operations but drew scrutiny for potential overexposure to underperforming contracts, as Webuild's debt rose to €3.5 billion post-transaction.

Integration and Post-Acquisition Outcomes

Webuild completed the acquisition of approximately 65% of Astaldi on November 5, 2020, through a capital increase under the Progetto Italia initiative, followed by the purchase of the remaining 33.9% stake from creditors by July 31, 2021, for €170 million. The focused on Astaldi's " business," encompassing viable ongoing projects and operations, which Webuild absorbed via a partial demerger approved in March 2021; Astaldi retained non-core assets and liabilities tied to debt restructuring for creditor settlement. This process enabled Webuild to consolidate Astaldi's contributions from the acquisition date, isolating problematic elements like underperforming international divisions for separate disposal. Financial outcomes post-integration reflected enhanced scale and performance for Webuild. In 2021, the merger contributed to projected group revenues of €6.5-7.2 billion, up from €5.3 billion in adjusted 2020 figures, with Astaldi's integration costs amounting to €32 million treated as one-off adjustments. By full-year 2021, Webuild achieved a record construction backlog exceeding €37 billion, bolstered by €11.3 billion in new orders distributed across core markets including Italy, with Astaldi's projects aiding diversification and backlog stability. Subsequent years showed sustained growth: first-half 2024 revenues rose 20% to €5.5 billion with an EBITDA margin of 7.5%, and second-quarter 2025 revenues hit $6.7 billion, a 22% year-over-year increase. Astaldi's former foreign operations, classified as discontinued post-integration, yielded a €6 million profit in 2024, compared to a €10 million loss in 2023, indicating stabilization of residual exposures. The acquisition earned Webuild the 2021 for its strategic value in consolidating Italian construction capabilities and supporting sustainable infrastructure relaunch amid sector fragmentation. Overall, the integration transformed Astaldi's viable assets into a growth driver for Webuild, mitigating prior debt risks through structural separation while enhancing competitive positioning in large-scale civil engineering.

Lessons from Astaldi's Decline

Astaldi's insolvency in 2018 underscored the perils of excessive leverage in the construction sector, where firms often finance large-scale infrastructure projects through debt amid cyclical cash flows. The company's €2.5 billion debt burden, exacerbated by high refinancing risks and depleted liquidity, highlighted how reliance on short-term borrowing without sufficient undrawn credit facilities can precipitate crisis during downturns. Italian banking sector exposure to such firms reached €102 billion, illustrating systemic vulnerabilities when construction defaults—already the highest in the economy—amplify broader financial instability. A core lesson emerged from Astaldi's dependence on delayed asset disposals and collections, particularly in concessions tied to emerging markets. The stalled sale of its stake in Turkey's Third Bosphorus Bridge, due to the 2018 Turkish economic turmoil involving lira depreciation and inflation, crippled liquidity as anticipated proceeds failed to materialize until March 2020. Similarly, bureaucratic slowdowns in , coupled with unpaid receivables and absent contract advances, stalled production and invited penalties, demonstrating how overexposure to politically sensitive or underfunded public projects erodes buffers against external shocks. Venezuela's and expropriation risks further inflicted impairment losses exceeding hundreds of millions from 2017 to 2019, underscoring the need for rigorous geopolitical risk pricing in international diversification. The episode also revealed deficiencies in operational resilience, including inflexible banking support and inadequate hedging against payment delays from public entities. Astaldi's filing for concordato preventivo (creditor protection) on September 28, 2018, and subsequent court admission on October 17, 2018, forced contract renegotiations and site slowdowns, amplifying losses through conservative asset valuations. For the this case advocates prioritizing cash-generative core competencies over speculative concessions, enforcing stricter clauses, and maintaining diversified financing to mitigate the causal chain from project delays to systemic default risks.

References

  1. [1]
    Company Astaldi SpA - MarketScreener
    Astaldi SpA is an Italy-based company primarily engaged in the construction industry. The Company structures its business into five main sectors: Transport ...
  2. [2]
    Astaldi | Infrastructure Finance & Investment - InfraPPP
    Astaldi SpA is a major construction company based in Rome, Italy. The group is active in the fields of civil, hydraulic, electromechanical and environmental ...Missing: history | Show results with:history
  3. [3]
    Financial Reports | Astaris - Astaldi
    2021 H1 RESULTS (ITALIAN VERSION), 2 August 2021. 2020. Full Year. 2020 Annual Financial Report (Italian version), 31 December 2020.Missing: history | Show results with:history
  4. [4]
    ASTALDI - 2025 Company Profile, Funding & Competitors - Tracxn
    Jun 7, 2025 · ASTALDI is an acquired company based in Rome (Italy), founded in 1929. It operates as a Provider of transport and energy infrastructure ...
  5. [5]
    Italian court admits Astaldi to creditor protection process - Reuters
    Oct 17, 2018 · The court has set Dec. 16 as the deadline for Astaldi to submit a final restructuring plan related to the arrangement with creditors, the ...
  6. [6]
    Astaldi files for concordato in bianco - Lexology
    Oct 4, 2018 · Astaldi, the Italian multinational construction company, filed on Friday (28 September) for concordato in bianco. This is an in-court restructuring proceeding.
  7. [7]
    Astaldi faces financial crisis - Railway PRO
    Sep 28, 2018 · Astaldi announced that the delay in the sale process of the Third Bosporus Bridge, due to Turkey's political and economic and financial events, has required ...
  8. [8]
    Troubled Astaldi exits US$200mn Chilean hospital project
    Jan 3, 2019 · SCMS accused Astaldi of not paying sub-contractors for several months. As a result, the concessionaire "will take all necessary actions to ...Missing: achievements controversies
  9. [9]
    Zeigler: One of the three companies bidding on I-10 bridge walked ...
    Jun 25, 2019 · According to Zeigler, Astaldi Construction Corp. abandoned four large road and bridge construction jobs in Florida. Astaldi's surety bondholders ...<|separator|>
  10. [10]
    Astaldi joins Webuild Group - We Build Value
    Jul 29, 2020 · The Court of Rome approves Astaldi's creditor composition proposal, paving the way for the investment of Webuild Group into the new Astaldi.
  11. [11]
    Webuild completes Astaldi acquisition - Construction Briefing
    Nov 6, 2020 · The deal, worth €225 million, means that Webuild now owns around 65% of Astaldi, which had recently come close to declaring itself bankrupt.
  12. [12]
    COURT APPROVES COMPOSITION PROCEDURE | Astaris - ASTALDI
    Jul 17, 2020 · “Approval of the Astaldi's composition procedure represents the positive outcome of a complex process that took approximately two years, which ...
  13. [13]
    Enforcement Of $146M Chilean Hospital Award Sought In Conn.
    Jan 3, 2025 · In particular, Sociedad argues Webuild assumed liability for Astaldi's post-bankruptcy debts in a spinoff and merger agreement. The company says ...
  14. [14]
    Astaris 2025 Company Profile: Valuation, Funding & Investors
    Astaris Overview · Year Founded. 1929. Year Founded · Status. Private · Employees. 3,893. Employees · Latest Deal Type. M&A · Financing Rounds. 8 · Investments. 13 ...<|separator|>
  15. [15]
    Astaldi - ProTenders
    In 1929 was founded the company Astaldi Construction and Public Works SpA Until the Second World War, the company operates mainly on the Italian territory ...Missing: history years
  16. [16]
    [PDF] Le nuove opere del 2014. - Astaldi
    Dec 31, 2014 · Tra gli anni '50 e gli anni '70 abbiamo accresciuto la dimensione e la complessità dei progetti realizzati con il tratto dell'Autostrada del ...
  17. [17]
    [PDF] 2017 Sustainability profile - Astaldi
    The Astaldi Group operates internationally in constructing large works with strong leadership in. Italy and abroad, where it operates in four continents. It ...
  18. [18]
    [PDF] Profilo di sostenibilità 2017 - Astaldi
    Anni '60-'70: Già dalla fine degli anni '50, Astaldi continua l'espansione ... Anni '80-'90: Il processo di riorganizzazione culmina nella fusione ...
  19. [19]
    [PDF] annual report - Astaldi
    Mar 9, 2016 · Our Group also expanded with the acquisition of Italstrade and Dipenta in the 1990s; we were able to expand our skills and supply systems ...
  20. [20]
    [PDF] 2004 - Astaldi
    Jan 17, 2003 · artistic world which was already inherent in the Company's founders. As founding shareholder, Astaldi contributes by supporting the activity ...Missing: Sante | Show results with:Sante
  21. [21]
    [PDF] To consolidate as leading Italian General Contractor and ... - Astaldi
    Feb 9, 2005 · ... expansion of the integrated trans- port system planned for Milan. The planned duration of the works including the de- sign phase is 5 years ...
  22. [22]
    [PDF] annual report - Astaldi
    Dec 29, 2012 · Astaldi Group is among the leading. General Contractors in Italy and among the most important in. Europe. As regards Transport Infra- structures ...
  23. [23]
    [PDF] H1 2010 RESULTS - Astaldi
    ▻ Revenues increase reflects the strategic guidelines to expand into neighboring markets. ▻ In America, activities in Venezuela are being reduced to < 10 ...
  24. [24]
    ASTALDI 2006-2010 BUSINESS PLAN APPROVED. TOTAL ...
    Jul 18, 2016 · The Board of Directors of Astaldi S.p.A., chaired by Ernesto Monti, has examined and approved the new Business Plan for 2006-2010.
  25. [25]
    [PDF] Company presentation - Astaldi
    The 1st project finance in Italy and one of the first in Europe, developed in the urban transport sector. ▫ “European Transport (Light Rail) Deal of the Year” ...Missing: 1929-1950 | Show results with:1929-1950
  26. [26]
    [PDF] 2017. Future and concreteness. - Construction means ... - Astaldi
    Dec 31, 2018 · the year when the engineer Sante Astaldi established the individual firm bearing his name: inventiveness, construction know-how and skills ...Missing: founding | Show results with:founding
  27. [27]
    FY 2017 Results | Astaris - Astaldi
    Mar 15, 2018 · Financial operations were affected by the average levels of debt and support to production and commercial activities in areas, such as the ...Missing: crisis | Show results with:crisis
  28. [28]
    [PDF] Astaldi's crisis follows that of other well-known names amongst the ...
    Nov 10, 2017 · The Venezuela affair was partly responsible, having driven the construction company to devalue its exposure towards the country for 230 million.Missing: controversies | Show results with:controversies
  29. [29]
    Italy-Based Engineering And Construction Group As - S&P Global
    Oct 2, 2018 · As at June 30, 2018, Astaldi reported net financial position stood at €1.9 billion, and gross debt totalled €2.5 billion. The issuer credit ...
  30. [30]
    [PDF] press release information requested by consob pursuant to art. 114 ...
    Nov 16, 2018 · At 30 September 2018, Astaldi Group recorded a Total Net Financial Debt (as per ESMA memorandum dated 10. February 2005) of EUR 2,013.1 million ...
  31. [31]
    Fitch Downgrades Astaldi to 'C' on Creditor Protection Application
    Oct 1, 2018 · Fitch Ratings has downgraded Astaldi SpA to 'C' from 'CCC-' and removed it from Rating Watch Evolving. The downgrade reflects that Astaldi had filed for ...
  32. [32]
    https://www.cdsdeterminationscommittees.org/documents/2018/10/astaldi-dc-statement-october-9-2018.pdf
  33. [33]
    Astaldi Nears A Key Deadline In Its Restructuring - Seeking Alpha
    Dec 11, 2018 · On September 28, Astaldi requested the Italian court to allow a procedure of “composition with creditors” aimed at “guaranteeing the regular ...Missing: achievements controversies
  34. [34]
    [PDF] Building a stronger Astaldi
    May 16, 2018 · Expertise in handling full life cycle of PPP projects. Competitive ... Top 10 construction projects by share of backlog at Dec-17A.
  35. [35]
    [PDF] ASTALDI @ STAR Conference
    building on our core skills and market strengths. 2 Disciplined project selection based on. Astaldi's skills, assets and heritage. 3. Maximize long-term value ...
  36. [36]
    Astaldi - Products, Competitors, Financials, Employees ... - CB Insights
    When was Astaldi founded? Astaldi was founded in 1929. Where is Astaldi's headquarters? Astaldi's headquarters is located at Via Adige, 19, Milan.Missing: history early
  37. [37]
    [PDF] MOODY'S DOWNGRADES ASTALDI'S RATING
    Sep 10, 2018 · With a leading position in Italy, Astaldi is one of the world's top 50 construction firms, one of Europe's top 25 contractors, and is also a ...Missing: expertise | Show results with:expertise
  38. [38]
    [PDF] Annual Report - Astaldi
    Feb 3, 2021 · Financial position and performance of the parent. Astaldi S.p.A.. Financial performance of Astaldi S.p.A.. The Reclassified Statement of Profit ...
  39. [39]
    Business Model - Astaldi
    Feb 5, 2021 · This approach allows the Group to pursue sustainable levels of profitability, by acquiring contracts awarded according to a variety of elements.
  40. [40]
    2017-2021 Strategic Plan | Astaris - Astaldi
    Aug 8, 2017 · 2017-2021 Strategic Plan. Attachments: Presentation (pdf) · Conference Call (audio). Last updated: Aug 08 2017.
  41. [41]
    [PDF] 2016. A yearlong journey. - Astaldi
    Dec 31, 2018 · The ELT will be built on Cerro Armazones in Chile, a country where we are already a major player in the hospital sector and are building an ...
  42. [42]
    [PDF] Astaldi Group Annual Financial Report
    Dec 31, 2016 · ASTALDI is representative of Italy as regards infrastructures. It has long exported technology, know-how and innovative solutions for customers ...
  43. [43]
    Webuild results at December 31, 2020
    Mar 21, 2021 · Gross debt amounted to € 3,560.2 million, up € 1,290.2 million compared to December 31, 2019 (€ 2,270.1 million) due to the full use of the ...
  44. [44]
    BIM Implementation for Design, Construction and Hand-Over on ...
    This class covers the implementation of an integrated BIM system inside the Design and Construction Joint Venture (VCGP + ASTALDI) of the Santiago de Chile ...
  45. [45]
    Leaked 2016 Nalcor document describes 'serious deficiencies' in ...
    Dec 13, 2018 · "Astaldi's performance was the result of, but not limited to, poor planning, lack of discipline, failure to supervise, rework, extended break ...
  46. [46]
    How the Astaldi problem forced Nalcor to pay an extra $700M ... - CBC
    May 23, 2019 · The worry was that if Astaldi failed, it would have a serious cascade effect on the entire project, and drive costs even higher, or what Clarke ...
  47. [47]
    Fitch Downgrades Astaldi to 'B'; Outlook Negative
    Nov 21, 2017 · The Outlook is Negative. The downgrade reflects Astaldi's failure to delever its capital structure in line with Fitch's expectations. The ...
  48. [48]
    Fitch Downgrades Astaldi to 'CCC-', Places on Rating Watch Evolving
    Sep 7, 2018 · Should the company fail to dispose of the assets, it will have to refinance its short-term debt or seek other financing options. SUMMARY OF ...<|separator|>
  49. [49]
    Naples-Bari High Speed Railway Project
    Mar 26, 2017 · The Salini Impregilo (60%) and Astaldi (40%) consortium was awarded a €397m ($428m) contract to design and construct the Naples to Cancello ...
  50. [50]
    ASTALDI: WILL BUILD A NEW SECTION OF THE NAPLES-BARI ...
    Mar 29, 2019 · Astaldi Group has been awarded in joint venture a contract worth EUR 608 million to build additional 18.7 kilometres of the Naples-Bari ...
  51. [51]
    Main projects | Astaris - Astaldi
    NEW HOSPITAL IN MONOPOLI FASANO ; Marche-Umbria Quadrilateral Highway ; JONICA NATIONAL ROAD – Megalot 3 ; Gdansk waste-to-energy plant.Missing: origins 1929- 1950s
  52. [52]
    [PDF] astaldi, eur 110 million in new orders in italy green light from the ...
    Rome, 28 February 2018 – Astaldi announces having been awarded two construction contracts in Italy totalling EUR 110 million for Astaldi's share.
  53. [53]
    Selected disclosure for the first 9 Months of 2020 | Webuild Group
    Nov 10, 2020 · Genoa Railway Hub: The project envisages the completion of civil works on the Colombo, San Tomaso and Polcevera tunnels for € 120 million in 30 ...<|separator|>
  54. [54]
    Astaldi signs 356 mln euro contract to build motorway section in ...
    May 12, 2020 · The Astaldi Group has been present for more than 25 years in Romania, where it has built more than 100 km of railways and undergrounds, 250 km ...<|separator|>
  55. [55]
    OPENING TO TRAFFIC OF TRANSYLVANIA MOTORWAY ... - ASTALDI
    Sep 30, 2020 · Astaldi Group has opened to traffic the Ogra–Campia Turzii motorway sections, which forms part of the A3 Transylvania Motorway, and the Ciurel Motorway ...
  56. [56]
    NEW CONTRACT IN ROMANIA WORTH EUR 356 MILLION - ASTALDI
    May 12, 2020 · Astaldi Group signed a contract worth EUR 356 million for the construction of more than 30 kilometres of the Sibiu-Pitesti Motorway, ...
  57. [57]
    Cables up for Romania's Brăila Bridge | Global Highways
    The Astaldi and IHI Infrastructure Systems joint venture reports that work will soon start on the road deck for Romania's Brăila Bridge.
  58. [58]
    Braila Bridge, the longest suspension bridge in Romania, opened - IHI
    Jul 7, 2023 · This road and bridge development project has a total length of over 23km including the suspension bridge over the Daunbe River (1974,30m, center span 1120 m, ...<|control11|><|separator|>
  59. [59]
    Italian group Astaldi will revamp another 36 km of railway in ...
    The work will include earthworks and consolidation on a segment of 36 kilometers, building 17 bridges, modernizing five bridges, one tunnel, and seven passages.
  60. [60]
    [PDF] ASTALDI, NEW CONTRACTS IN TURKEY
    Apr 11, 2017 · The ASTALDI GROUP has been operating for more than 30 years in Turkey, where it is currently engaged in completing the projects under concession ...
  61. [61]
    INAUGURATION OF THE THIRD BRIDGE OVER THE ... - ASTALDI
    Aug 25, 2016 · The inauguration of the Third Bosphorus Bridge – the widest suspension bridge in the world with towers taller than the Eiffel Tower – will take place tomorrow ...
  62. [62]
    SOLD THE THIRD BOSPHOROUS BRIDGE IN TURKEY - ASTALDI
    Mar 19, 2020 · It has signed the closing on the sale of its interest in the concession for the construction and operation of the Northern Marmara Highway (the “Third Bridge”) ...
  63. [63]
    Italy's Astaldi signs $600 mln financing deal for motorway project in ...
    Jul 31, 2014 · ISTANBUL (Turkey), July 31 (SeeNews) – Italian general contractor Astaldi said it has signed a $600 million (448 million euro) financing ...
  64. [64]
    Astaldi and Partners Weigh Sale of $7 Billion Turkish Road
    Jan 29, 2019 · Astaldi SpA, the cash-strapped Italian builder, and its Turkish partners are looking into the possible sale of their Istanbul-Izmir toll ...
  65. [65]
    Italian construction firm Astaldi withdraws from Türkiye's largest ...
    Mar 5, 2025 · Italian construction giant Astaldi is reportedly in talks to transfer its entire 51% stake in Türkiye's largest healthcare complex, ...
  66. [66]
    Astaldi Construction Corporation USA - LinkedIn
    Astaldi Construction Corporation has two main business units: Heavy Civil Infrastructure Projects; Procurement and Engineering Services.
  67. [67]
    ASTALDI, NEW ORDER IN THE USA FOR 108 MILLION DOLLARS
    Jan 15, 2018 · Astaldi announces it has been awarded the US$ 108 million contract to build a section of the Wekiva Parkway in Florida ( United States ).Missing: North | Show results with:North
  68. [68]
    Contractor picked for $1.6B part of Florida DOT work Astaldi ...
    Apr 17, 2019 · The Florida DOT announced earlier this month that Astaldi Construction Corp. has voluntarily defaulted on four state highway projects (details ...Missing: American | Show results with:American
  69. [69]
    N.L. Hydro claims victory in Muskrat Falls arbitration dispute with ...
    May 20, 2022 · Astaldi Canada, a subsidiary of a major Italian construction company, was awarded a $1.1-billion contract in late 2013 to build the intake ...
  70. [70]
    ASTALDI AND MUSKRAT FALLS CORPORATION REACHED ...
    Dec 21, 2016 · Astaldi is responsible for the construction of the powerhouse, intake and spillway civil works for the Muskrat Falls generation facility.
  71. [71]
    Astaldi receives stop work order for 824-MW Muskrat Falls hydro ...
    Oct 19, 2018 · Nalcor Energy has issued a stop work order to Astaldi Canada Inc., the main contractor on its 824-MW Muskrat Falls hydro project.
  72. [72]
    Astaldi issued maximum fine, found guilty of 'professional ... - CBC
    Jun 4, 2020 · The main contractor for the Muskrat Falls powerhouse was carrying out structural engineering without a permit when a wooden formwork ...
  73. [73]
    Astaldi wins contracts worth €400m in Chile, Honduras and Poland
    Nov 24, 2017 · Italian construction group Astaldi has won three construction contracts for projects in Chile, Poland and Honduras worth almost €400m.
  74. [74]
    Astaldi wins two new contracts - Construction Briefing
    May 15, 2018 · Astaldi Group has been awarded two new construction contracts worth a combined total of €193million (US$231 million) for projects in Chile and Mexico.
  75. [75]
    Salini Impregilo and Astaldi in Mobilinx Consortium awarded ...
    Oct 21, 2019 · The Hurontario LRT project in Ontario is the latest in our drive to expand in North America, where the United States represents our single ...
  76. [76]
    More blame for Astaldi as manager fingers contractor for Muskrat ...
    May 30, 2019 · Astaldi failed to perform," O'Brien said bluntly during ... project was a disastrous failure costing several hundred million dollars.Missing: wins | Show results with:wins
  77. [77]
    [PDF] Astaldi awarded major Muskrat Falls contract
    Oct 10, 2013 · It has an estimated value of about $1 billion, though that number has been floated by industry and is not confirmed by Nalcor Energy. Nalcor has ...
  78. [78]
    Audit finds Muskrat Falls cost overruns became obvious soon after ...
    Feb 18, 2019 · The audit attributes $1.2 billion in cost overruns to Astaldi, mainly due to performance issues with speed and work standards that did not align ...
  79. [79]
    blame for Astaldi as manager fingers contractor for Muskrat setbacks
    May 30, 2019 · "Astaldi was a problem contractor at Muskrat Falls. Astaldi failed to perform," O'Brien said bluntly during testimony Thursday at a public ...
  80. [80]
    [PDF] From the Chair Closing the Justice Gap: Qualified Representatives?
    Astaldi undermined competition by materially underbidding the project. In doing so, the ALJ noted that “Astal- di's only 'deviation' was bidding a lower ...<|control11|><|separator|>
  81. [81]
    CEO issues caution on Muskrat Falls contracting | PNI Atlantic News
    Of the other three bidders, one is a partnership known as IKC-ONE Civil Constructors, then there is Astaldi ... underbidding, calling it “a legitimate concern.”.
  82. [82]
    Italian Builders Add $118 Billion Worry to Banks' Problems
    Oct 11, 2018 · Last month Astaldi, Italy's second-largest builder, filed for creditor protection and has until March to present a restructuring plan to avoid ...Missing: details | Show results with:details<|separator|>
  83. [83]
    Research Update: Italy-Based Astaldi SpA Downgrad | S&P Global ...
    Astaldi's €500 million RCF and other credit facilities are subject to three step-down financial covenants, including net debt-to-EBITDA and net debt-to-equity ...Missing: figures | Show results with:figures
  84. [84]
    [PDF] Building a stronger Astaldi
    Jun 30, 2018 · Astaldi core EBITDA1 % …maintaining solid profitability… De-risking strategy… Profitability expected to remain solid, adjusted for a ...
  85. [85]
    Inside Goldman Sachs's Play to Squeeze Italy's Riskiest Credit
    Jun 21, 2018 · In the case of Astaldi, which has struggled to make money for the last decade, Goldman has taken that role a notch further, setting off a scrap ...<|separator|>
  86. [86]
    ASTALDI: IMPOSSIBILITY TO ISSUE AN OPINION ON THE 2018 ...
    Jul 13, 2020 · ASTALDI: IMPOSSIBILITY TO ISSUE AN OPINION ON THE 2018 FINANCIAL STATEMENTS AND THE 2019 FINANCIAL STATEMENTS BY THE AUDITING FIRM DUE TO ...Missing: crisis | Show results with:crisis
  87. [87]
    [PDF] submission of astaldi canada inc. to the commission of inquiry
    Said clauses direct the. Commission to inquire as to why there are significant differences between the estimated costs of the Muskrat Falls Project at the time ...
  88. [88]
    [PDF] CIMFP Exhibit P-03672 Page 1
    Astaldi claims for an estimated $20,530,000 for the costs arising from the escalation. The details underlying Astaldi's claim are set out in Annex E. 7.0.
  89. [89]
    Astaldi aided by Nalcor cash | PNI Atlantic News - SaltWire
    Supplemental financial agreements were made between Astaldi and Nalcor as the project progressed and was disrupted by change orders, disputes and a lagging ...
  90. [90]
    Millions in lien claims target unpaid bills by Muskrat Falls contractor ...
    Sep 27, 2018 · The principal contractor at Muskrat Falls, Astaldi Canada Inc., has failed to remit $7.8 million to benefit plans for unionized workers at ...Missing: disputes | Show results with:disputes
  91. [91]
    Astaldi did not meet payroll at Muskrat Falls site: trades council
    Oct 25, 2018 · The Muskrat Falls Corporation and Astaldi Canada Inc. have also gone to Newfoundland Supreme Court over contract arbitration issues. Article ...Missing: lawsuit | Show results with:lawsuit
  92. [92]
    Astaldi Canada vs. Muskrat Falls Corp | SOCOTEC US
    PROJECT DETAILS: SOCOTEC was engaged by concrete contractor Astaldi to provide Dispute Resolution support services on the Muskrat Falls Power Plant Project ...
  93. [93]
    Muskrat Falls Inquiry Has Opened Door To Hundreds Of Millions In ...
    May 24, 2019 · Muskrat Falls Inquiry Has Opened Door To Hundreds Of Millions In Claims, Says Project Manager ... Astaldi filed its arbitration. He says the ...
  94. [94]
    N.L. Hydro claims victory in Muskrat Falls arbitration dispute with ...
    May 20, 2022 · A source with knowledge of the matter said contractors and suppliers who were owed money following Astaldi's termination have either been paid ...
  95. [95]
    Webuild submits an offer to enter into Astaldi's equity with business ...
    Feb 13, 2019 · The Proposal envisages: (i) an economic and financial plan to support the restructuring and continuity of Astaldi's EPC activities; (ii) the ...
  96. [96]
    Italy's Salini offers Astaldi 225 mln euro rescue | Reuters
    Italy's Salini Impregilo has offered to invest 225 million euros ($254 million) to rescue troubled rival construction group Astaldi, the company said on ...
  97. [97]
    Salini Impregilo Offers Rescue Purchase of Astaldi Group | 2019-02-14
    Feb 14, 2019 · Salini Impregilo's offer includes a $325-million cash injection to repay protected creditors and keep Astaldi in business after selling off ...
  98. [98]
    Construction Giant Makes $1.7 Billion Bet to Rebuild Italy - Bloomberg
    Jul 9, 2019 · Italy's top builder to unveil rescue plan for troubled Astaldi · Salini's Project Italy would put several firms under one roof.
  99. [99]
    Astaldi Rescue Deal Meets Resistance From Two Italian Lenders
    With two weeks to go before a deadline to save Astaldi SpA, two of its largest lenders are resisting calls to inject equity to support a ...
  100. [100]
    ASTALDI: UPDATE OF THE OFFER FROM SALINI IMPREGILO
    Jul 16, 2019 · The Board of Directors of Astaldi S.p.A. makes known that it has received from Salini Impregilo (“SI”) an update of the investment offer ...Missing: rescue | Show results with:rescue
  101. [101]
    Salini Impregilo Appears Set To Pick Up Astaldi, Go After US Projects
    Jul 2, 2019 · Astaldi, Italy's third largest construction group, filed for bankruptcy in September 2018 after being unable to counter debt problems by selling ...Missing: achievements controversies
  102. [102]
    Webuild successfully completes acquisition of Astaldi via capital ...
    Nov 5, 2020 · Webuild announces the completion of its acquisition of 65% of Astaldi, the most important acquisition conducted under Progetto Italia (Project Italy).Missing: 1990s Italstrade Dipenta
  103. [103]
    Webuild Acquires Majority of Astaldi | 2020-11-06
    Nov 6, 2020 · ... Planning and Execution ... Discover how coordinated early-stage practices deliver more resilient, cost-effective, high-performing projects.
  104. [104]
    Astaldi integration | Webuild Group
    The integration of Astaldi is the most important project to be carried out for the relaunch of the Italian infrastructure sector. Pietro Salini, CEO Webuild ...Missing: international presence
  105. [105]
    Agreed exchange ratio, timing and procedure for Webuild and ...
    Mar 14, 2021 · Board of Directors of Webuild SpA and Astaldi SpA have agreed to proceed with a partial and proportional spin-off of Astaldi in favour of Webuild.Missing: international | Show results with:international
  106. [106]
    Webuild S.p.A. completed the acquisition of remaining 33.9% stake ...
    Jul 31, 2021 · On April 29 and April 30, 2021, respectively, the shareholders of Webuild and Astaldi approved the merger. The Boards of Directors of Webuild ...
  107. [107]
    Acquisition | ASTALDI SPA | 2nd August 2021 - Solactive
    Jul 28, 2021 · Acquisition | ASTALDI SPA | 2nd August 2021. Due to the acquisition of ASTALDI SPA by WEBUILD SPA, the following treatment will be applied ...Missing: details | Show results with:details
  108. [108]
    Consolidated Financial Results at June 30, 2021 | Webuild Group
    Jul 28, 2021 · On November 5, 2020, Webuild finalised the acquisition of approximately 67% of Astaldi Group. Astaldi was consolidated from the date that ...Missing: post- outcomes
  109. [109]
    ASTALDI AND WEBUILD MERGER LAUNCHED | Astaris
    Mar 15, 2021 · The project envisages Webuild to assume ownership of Astaldi's Continuity Business while Astaldi will retain the assets and liabilities ...Missing: outcomes | Show results with:outcomes
  110. [110]
    https://realty.economictimes.indiatimes.com/news/industry/webuild-sees-2021-revenues-growing-to-6-5-7-2-billion-euros-with-astaldi-merger/81635358/
  111. [111]
    [PDF] Full Year 2021 Financial Results March 18, 2022 - Webuild
    ... result related to the acquisition of Astaldi. (2) Figures adjusted by €32m of one-off costs, mainly related to Astaldi integration, to represent Group ...Missing: onwards | Show results with:onwards
  112. [112]
    Webuild results at June 30, 2024
    Jul 25, 2024 · At the operational level, Webuild performance continued to grow. Revenues increased by 20% to €5.5 billion with an EBITDA margin of 7.5% to €407 ...Missing: merger | Show results with:merger
  113. [113]
    Earnings call transcript: Webuild Q2 2025 sees strong growth amid ...
    Jul 29, 2025 · This performance underscores Webuild's strategic focus on sustainable infrastructure and its ability to capitalize on booming markets in key ...<|separator|>
  114. [114]
    Webuild Results at December 31, 2024
    Mar 13, 2025 · The result from discontinued operations showed a profit of €6 million (a loss of €10 million in 2023). It refers to the former Astaldi foreign ...Missing: onwards | Show results with:onwards
  115. [115]
    #Webuild wins 2021 KPMG M&A Awards - 17th edition ... - Facebook
    May 14, 2021 · "The integration of Astaldi creates real value for #Italy as it will help relaunch the development of sustainable #infrastructure, the economy ...Missing: onwards | Show results with:onwards
  116. [116]
    The Board of Directors approves the financial statements ... - ASTALDI
    It must be recalled that the main causes that led to the Group's financial crisis include (i) slowdown of production activities in Italy caused by ...
  117. [117]
    Astaldi Seeks Creditor Protection After Turkey Sale Delayed (2)
    Sep 28, 2018 · Astaldi SpA is filing for creditor protection in a Rome court after Turkey's economic crisis put the brakes on an asset sale in Istanbul ...Missing: underbidding | Show results with:underbidding